TEST TW WEATHER

NOTICE TO RECEIVE SEALED BIDS

The City of Chattahoochee will receive sealed bids from any qualified person, company or corporation interested in constructing the: RIVER LANDING RV PARK IMPROVEMENTS


This project will include improvements to the existing RV park located on River Road in Chattahoochee, Florida. The proposed improvements will include the resurfacing of the existing paved driveway, site fencing, new water, sewer, and electric services, and improvements to existing RV spaces.


Bid documents can be obtained at Dewberry Engineers Inc., 20684 Central Avenue East, Blountstown, Florida 32424, (850) 674-3300. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. Completion date for these projects will be 60 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day. Please indicate on the envelope that this is a sealed bid for the “RIVER LANDING RV PARK IMPROVEMENTS”. Bids will be received until 10:00 AM (EST) on March 19, 2020 at the Chattahoochee City Hall, 22 Jefferson Street, Chattahoochee, FL 32324, and will be opened and read aloud on March 19, 2020 at 10:00 AM (EST).


Cost for Plans and Specifications will be $50.00 per set and is non-refundable. Checks should be made payable to DEWBERRY ENGINEERS INC. The City of Chattahoochee reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of the City of Chattahoochee. If you have any questions, please contact Matthew Chester via phone at (850) 674-3300 or email at [email protected]