TEST TW WEATHER

NOTICE TO RECEIVE SEALED BIDS

The City of Chattahoochee will receive sealed bids from any qualified person, company or corporation interested in constructing the:

TORREYA ROAD & DICKSON STREET EROSION REMEDIATION

This project will include backfill of the erosion area, concrete ditch paving, 36” RCP extension and headwall, Rip-Rap bank and shore, and sod.

Bid documents can be obtained at Dewberry Engineers, Inc., 20684 Central Avenue East, Blountstown, Florida 32424, (850) 674-3300.  The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.

Completion date for these projects will be 60 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day. Please indicate on the envelope that this is a sealed bid for the “TORREYA ROAD & DICKSON STREET EROSION REMEDIATION”. Bids will be received until 10:00 am (EST) on   01/29/2020   at the Chattahoochee City Hall, 22 Jefferson Street, Chattahoochee, FL 32324, and will be opened and read aloud on     01/29/2020           at   10:00 am  (EST). Cost for Plans and Specifications will be $50.00 per set and is non-refundable.  Checks should be made payable to DEWBERRY ENGINEERS, INC.

The City of Chattahoochee reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of the City of Chattahoochee. If you have any questions, please contact Matthew Chester via phone at (850) 674-3300 or email at [email protected].